Design and execution of interior decoration: Interior decoration is a harmonization designed to bring colors, furniture, and other objects to an artistic image in a room or building. Interior decoration, like other arts, has a style, context, and principles that change according to the tastes and needs of each period. Interior architecture is in fact the creation of space, a space that has the necessary efficiency while being beautiful and effective. By combining the principles and specialized elements of interior architecture with a sense of aesthetics, the designer creates an atmosphere that represents the identity, needs, perceptions, and desires of the other party.

Interior decoration is the link between architecture and interior design. This field, like architecture, is related to the building and its components and elements on the one hand, and on the other hand, like interior design, it focuses on interior spaces. The science of architecture is related to issues on a metropolitan scale, but the field of interior architecture is at the human scale and in relation to public and personal spaces, and the result is man’s connection to the world around him. In addition to having sufficient knowledge in the field of architecture, the interior architect analyzes the sense received from architectural spaces in a way that creates a sense of belonging and integrity in the space, in other words, deals with the architecture of the space from the perspective of residents or users.

When entrusting the design and execution of your interior decoration to a contractor, one of the most important things you need is to have a proper contract that includes all the terms and conditions of the contract. Below is an example of a contract for the design and execution of interior decoration so that you can better master the subjects of your work. Or you can leave this matter to us and through the online service of GC Perfect, find the contractor you want to design and execute interior decoration, and easily and without any worries, hand over your smart contracts to the contractor.

Sample contract for designing and executing interior decoration

1. Specifications of the parties to the contract

1. 1 Employer Profile:

Mr / Ms / Company ……… to management/agency…… to national number/registration number …… to address …….. landline number. …… and the mobile number is …….

1. 2 specifications of the contractor:

Mr / Ms / Company ……… to management/agency…… to national number/registration number …… to address …….. landline number. …… and the mobile number is …….

2. The subject of the contract and the place of its performance

The subject of the contract includes design, executive operations and preparation, provision of equipment, renovation, creation of interior decoration, and subsequently (after performing matters related to design and interior decoration) installation of furniture and necessities of building floors according to Annex No. ….. The employer is attached to the contract.

Project location at ……. which has a building permit number ….. Date … / … / …..

3. Calculations and technical specifications of the project

3. 1 Design and decoration style based on classical methods with a combination of Roman facade based on pre-designed design patterns mentioned in Article 6.

3. 2 buildings have …. floors, the total infrastructure of which is ….. square meters; Each floor has …. square meters of infrastructure, which includes walls and ceilings ….. square meters.

3. 3 sections related to the possibility of installing lighting systems with dimensions of …. square meters and a special type of lighting and halogen installation called ….. is used.

3. 4 types of materials used in the project are …. and in case of destruction, design, and reconstruction according to the pattern, materials ….. are needed.

3.5 Each unit of the building has a split, gas oven, desktop gas, etc., which are separated before the project and after installation, are installed.

3. 6 buildings for each floor have the number of …. stairs and the number of …. steps, which in total the whole building …. steps and …. steps.

3. 7 dimensions of walls and ceilings that need to be painted in the area …. for each floor and in total …. square meters.

4. Contract cost (separately and in general)

4. 1 The total cost of the contract is …… $, which after fulfilling the subject of the contract and other obligations described in Article 12, after the approval of the employer’s supervisor, by presenting an official and valid invoice by the contractor, and after calculating legal deductions within ….. The working day is done by the contractor.

4. The two minor and separate costs of the contract are as follows:

4. 2. 1 The cost of preparing materials such as plaster, cement, brick, etc. is determined by the value of ….. $ per square meter.

4. 2. 2 The cost of preparing the paint is determined by the value of …. $ per square meter.

4. 2. 3 The cost of preparing and purchasing a lighting system with grade quality …. and brand …. is worth …. $ per square meter; And halogen parts are calculated in terms of number worth ….. Rials.

4. 2. 4 The cost of preparing and installing wood or MDF in the bedroom and kitchen is determined by the value of ….. $ per square meter.

4. 2. 5 Removal of installation and installation of equipment in the building such as split, desktop gas, etc. In total, the removal and re-installation are determined at a value of …. $.

5. Payment terms

5. 1 amount …… $ equivalent to ….. percent of the total value of the contract will be paid at the time of the contract (in exchange for receiving a guarantee check worth ……. $ to the number … ..).

5. 2 amount …… $ equivalent to …… percent of the total value of the contract after 50% of the work with the approval of the workshop supervisor.

5. 3 amount …… $ equivalent to …… percent of the total value of the contract after the completion of the project with approval (selected regulatory body).

5. 4 amount …… equivalent to …… percent of the total contract value after the end of the warranty period and elimination of possible defects (warranty period ….).

6. Documents of the contract

This contract includes the following documents:

A- Contract document (forthcoming contract).

B- General, detailed and executive plans:

1. Plans of the building location plan and layout plan

2. Executive detail and design drawings

3. Electrical installation plans

4. and …

7. Duration of the contract

The full duration of the project is ……….. working days and the start date of the contract is ………… and the end date of the contract is ………… … is.

8. Delays of the parties in carrying out the project

If the contractor, without permission from the employer to extend the contract date, attempts to delay the execution of the work, for each day of delay after the expiration of the daily contract date ………….. $ as a penalty for delay of the contractor’s claims Deducted.

On the other hand, if the employer somehow delays the execution of the project, with the approval of the workshop supervisor, the contract execution period will be increased accordingly.

9. monitoring

Supervision in the implementation of the obligations undertaken by the contractor in accordance with the provisions of this contract and its attached documents shall be the responsibility of the employer and/or his representative or the supervisory body introduced by the employer. The contractor is obliged to perform the works according to the contract, technical principles, and orders of the employer / or his representative / or the monitoring device, according to the specifications, documents, and documents attached to this contract.

10. Equipping and dismantling the project site workshop

The costs related to equipping and dismantling the workshop where the interior decoration operation is performed are the responsibility of the parties with the agreement of …. He must equip the workshop in such a way that the work starts and continues until the temporary delivery, without interruption and with the necessary quality. At the end of the work, he must take action to remove the materials from the destruction, the recycled materials from the destruction belong to …..

11. Maintaining the percentage of project progress and work materials

The contractor is obliged to maintain the percentage of project progress as well as the materials that are considered in the situation, including what is in the workshop or outside it in warehouses, etc., in an appropriate manner, and in the absence of damage. To compensate.

12. Contractor obligations

12. 1 The contractor is obliged to complete the subject of the contract within ….. working days from the date of signing the contract.

12. 2 In case of many projects taken by the contractor and no timely violation of the work process, the contractor is obliged to introduce a person as a representative to the employer before the start of the executive operation to make the necessary arrangements.

12. 3 Control and observance of safety points and implementation of necessary measures to prevent accidents for executive agents as well as liability for damage to property and third parties as a result of executive operations The subject of this contract is the responsibility of the contractor and in this regard no responsibility The employer will not notice.

12. 4 In accordance with the agreement between the employer and the contractor, the execution of the contract is dependent on the contractor, and the contractor has no right to transfer the subject of the contract to others.

12. 5 The contractor is obliged to perform executive operations during the working hours announced by the employer.

12. 6 The contractor is obliged to insure his employees during the period of employment and to take civil liability for all the activities of his employees during his employment in the insurance project. If during the contract any of the employees suffer a permanent or temporary disability or leads to death or is harmed by the activities of his employees, the employer has no responsibility and the contractor must be held accountable.

12. 8 The contractor is obliged to pay all the salaries and benefits of his employees and the employer is not responsible for the employer’s failure to do so.

12. 9 In accordance with the subject of the contract, the contractor must use first-class materials for use in the building, and any shortcomings and omissions in the realization of this importance are the responsibility of the contractor.

12. 10 The contractor undertakes to act with sufficient knowledge and information on all project documents, including the relevant plans and instructions, and at the time of concluding the contract, there is no point or issue incomprehensible to them.

12. 11 The contractor undertakes to deliver the equipment and supplies in the building, including cooling and heating splits, table gas, etc., safely, and must install and equip them safely.

12. 12 In case of technical defects and defects that lead to the order of demolition or repair of the structure, it is the responsibility of the contractor and is obliged to compensate for its negligence.

12. 12 In case of technical defects and defects that lead to the order of demolition or repair of the structure, it is the responsibility of the contractor and is obliged to compensate for its negligence.

12. 14 At the end of each working day, the contractor is required to wash and clean the workshop site so as not to disturb the comfort of neighbors.

12. 15 All transportation and handling of materials is the responsibility of the contractor.

12. 16 interior design processes including fireplace design, plastering the ceiling, kitchen, and rooms, flooring should be completely derived from classical architecture.

12. 17 The designer is required to submit the methods and plans to the approval of the employer or the supervising engineer before carrying out the construction operations.

12. 18 The contractor undertakes to observe the homogeneity of color selection when painting the relevant rooms and walls; In fact, it can be used in blue to make the rooms more relaxed and the other walls can be decorated with a combination of blue and yellow.

12. 19 The contractor is required to ensure that the cabinets and installations related to the kitchen are insulated against water leakage when using cabinets and aquarium glue.

13. Employer obligations

13. 1 The employer will issue the necessary remittances regarding the materials and supplies required by the subject of the contract, at the request of the contractor.

13. 2 The employer is obliged to provide a place for the employees to have a place for rest and eating, a sanitary service in the place of the workshop.

13. 3 Costs of water, electricity, and gas consumption required by the contractor, to carry out operations at the workshop and each floor separately is the responsibility of the employer.

13. 4 The employer undertakes to pay the contractor’s bill within ….. working days after each stage of the project implementation by the contractor, after the approval of the contract supervisor.

13. 5 The Contractor undertakes not to make any further changes after the approval of the designs and design methods by himself and the Supervising Engineer. Otherwise, any additional costs are directly borne by them.

14. Guarantee of good performance of obligations by the contractor

At the time of signing and exchanging the contract, the contractor undertakes to provide a guarantee of good performance of the obligations in the form of a bank guarantee and / or promissory note to the authorized signature of the company, which is equal to 5% of the total contract amount. If the employer violates the fulfillment of any of his obligations, he is free to confiscate and receive the guarantee documents within the framework of the contract up to the extent of the damage in his favor.

15. Surveillance device

Supervision over the implementation of the obligations undertaken by the contractor in accordance with the provisions of the contract will be the responsibility of ………. which is called the Surveillance device.

16. Project tax

Any taxes and legal deductions belonging to this contract are the responsibility of …….., which will be determined in accordance with the laws and regulations and will be deducted from other status deductions along with other legal deductions.

17. Cases of contract termination

17. 1 Transfer of the contract or assignment of operations to other natural or legal persons by the contractor.

17. 2 Failure to perform all or part of the contract on time.

17. 3 Delays in starting the project more than …………… days from the date of contract notification.

17. 4 Delays in the execution of work so as to indicate financial and technical incompetence and malice of the contractor.

17. 5 Absence without the permission of the contractor or termination of work without obtaining the written permission of the employer.

18. Disputes arising from the contract

Disputes arising from this contract will be resolved first through compromise between the parties and in case of non-compromise, by referring to the arbitration authority. The parties to the contract initially chose ………… as arbitration of the parties.

19. Miscellaneous items

19. 1 Emergency such as war, earthquake, lack of raw materials, etc. are reserved for the parties to the contract.

19. 2 In the event of any dispute between the parties to this contract, the matter will be settled through arbitration and the final judgment of the parties in this contract is the competent legal authorities.

19. The 3 cases not provided for in this contract will be based on the principle of freedom of will by agreement of the parties.

20. Copy of contract

The present contract in …….. Article and ……. copy has been prepared and signed by the parties and each copy has the same sentence.

Signature and fingerprint of the employer / or her legal representative Signature and fingerprint of the contractor / or her legal representative